Terms and Conditions

1. Acceptance of Terms

By accessing or using this website, submitting a contact form, requesting an estimate, approving a proposal, scheduling a service, signing a work order, making a payment, or allowing INTAMPA INC to begin work, you acknowledge that you have read, understood, and agreed to these Terms and Conditions.

If you do not agree to these Terms, do not use the website or authorize INTAMPA INC to perform services.

Website use alone creates an agreement concerning your use of the website. Service-related provisions become binding when these Terms are incorporated into an estimate, proposal, booking confirmation, work order, invoice, electronic acceptance process, or other agreement accepted by you.

2. Eligibility and Authority

You must be at least 18 years old and legally capable of entering into a contract to purchase services from INTAMPA INC.

When requesting work for a property, business, association, rental unit, or short-term rental, you represent that you are:

• The property owner.
• A tenant with authority to order the requested work.
• An authorized property manager, business representative, Airbnb host, agent, or other authorized decision-maker.
• Otherwise legally authorized to grant access and approve the services.

You are responsible for obtaining any required approval from an owner, landlord, condominium association, homeowners association, commercial landlord, insurer, tenant, occupant, lender, or other interested party before work begins.

3. Service Agreements and Order of Priority

Each project may be governed by one or more service documents, including an estimate, proposal, scope of work, booking confirmation, work order, change order, invoice, maintenance plan, or written service agreement.

If documents conflict, the following order of priority applies unless the parties expressly agree otherwise in writing:

1. A signed change order or project-specific amendment.
2. A signed service agreement, proposal, estimate, or work order.
3. A booking confirmation or recurring-service plan.
4. These Terms and Conditions.
5. General website descriptions or marketing materials.

Website descriptions, photographs, examples, and service summaries provide general information. They do not expand a project beyond the written scope accepted for that project.

4. Description of Services

INTAMPA INC provides property and facility services for homeowners, businesses, property managers, landlords, real estate professionals, and Airbnb hosts in Tampa Bay and Central Florida. Available services may include:

• General property maintenance.
• Commercial and residential cleaning.
• Common-area and amenity cleaning.
• Junk removal and property cleanouts.
• Interior painting and surface preparation.
• Minor drywall repairs and patching.
• General handyman services.
• Rental-property and short-term-rental preparation.
• Other nonregulated maintenance services described in an accepted service document.

The exact services, location, price, materials, exclusions, estimated schedule, and completion criteria are limited to the accepted service document.

INTAMPA INC may use qualified employees, independent contractors, subcontractors, suppliers, or specialty providers to perform or support a service. INTAMPA INC remains responsible for its contractual obligations except where a service document clearly identifies a separate provider with whom the customer contracts directly.

5. Service Limitations and Exclusions

Regulated and licensed work

INTAMPA INC does not agree to perform work that requires a state or local professional license, permit, certification, or regulated trade authorization unless that work is expressly included in a written service document and performed by a properly qualified provider.

Unless expressly agreed in writing, handyman services do not include structural engineering, major structural alterations, roofing, electrical contracting, plumbing contracting, HVAC contracting, gas work, fire-suppression work, alarm installation, architectural services, engineering services, or other work requiring specialized licensure.

Hazardous and specialized conditions

Standard cleaning, painting, drywall, maintenance, and junk-removal services do not include testing, handling, removal, transport, or remediation of:

• Asbestos or suspected asbestos-containing materials.
• Lead hazards or lead abatement.
• Mold remediation or professional mold assessment.
• Biohazards, bodily fluids, crime-scene materials, or medical waste.
• Hazardous chemicals, pesticides, fuels, explosives, or radioactive materials.
• Infestations requiring a licensed pest-control provider.
• Sewage, contaminated water, or regulated environmental waste.

If a suspected hazardous condition is discovered, INTAMPA INC may stop work, isolate the area when reasonably practical, and require inspection or remediation by a qualified specialist before services resume.

Inspections and professional opinions

Observations made by INTAMPA INC personnel are not engineering reports, environmental assessments, code inspections, mold assessments, pest inspections, structural inspections, or professional opinions. Customers should retain an appropriately licensed specialist when a condition requires specialized evaluation.

6. Estimates, Site Conditions, and Changes

Estimates

An estimate is based on the information, photographs, measurements, access conditions, and visible property conditions available when the estimate is prepared. Unless identified as a fixed-price proposal, an estimate is a good-faith projection and not a guarantee of the final cost.

Estimates may expire on the date stated in the estimate. If no expiration date is stated, the estimate expires 30 calendar days after issuance.

Hidden or changed conditions

Pricing and scheduling may change when actual conditions differ materially from the information supplied or from what could reasonably be observed before work began. Examples include:

• Concealed water damage, rot, corrosion, mold, pest activity, or structural movement.
• Additional layers of paint, drywall, flooring, adhesive, or other material.
• Unexpectedly heavy soil, grease, debris, staining, odors, or contamination.
• Restricted access, unavailable utilities, parking restrictions, or building rules.
• Incorrect measurements, photographs, descriptions, or quantities supplied by the customer.
• Changes requested after the estimate is accepted.
• Code, permit, safety, or manufacturer requirements not reasonably identifiable beforehand.

Change orders

Additional work requires customer authorization. Authorization may be documented through a signed change order, email, text message, electronic approval, updated estimate, payment authorization, or another written record showing agreement.

INTAMPA INC may stop work until a change in scope, price, materials, or schedule is approved.

7. Customer Responsibilities

The customer agrees to:

• Provide accurate and complete information about the property and requested work.
• Disclose known hazards, damage, leaks, mold, asbestos, lead-based paint, pests, unsafe wiring, structural concerns, or other dangerous conditions.
• Identify fragile, valuable, irreplaceable, or unusually sensitive property before work begins.
• Remove or secure cash, jewelry, medications, firearms, confidential records, collectibles, electronics, and other valuables.
• Provide safe and lawful access to the work area.
• Provide working electricity, water, lighting, climate control, and sanitary facilities when reasonably required for the service.
• Keep children, occupants, guests, employees, and unauthorized persons away from active work areas.
• Secure pets and disclose animals that may create an access or safety concern.
• Provide accurate gate codes, alarm instructions, parking directions, elevator reservations, loading access, and building requirements.
• Obtain required owner, landlord, association, tenant, or business approvals.
• Review and approve colors, finishes, materials, dimensions, quantities, and placement before installation or application.
• Inspect completed work and report concerns promptly.
• Pay all amounts due under the accepted service documents.

INTAMPA INC is not responsible for delay, additional cost, or incomplete performance caused by the customer’s failure to meet these responsibilities.

8. Property Access and Job-Site Safety

Access authorization

By providing a key, code, lockbox combination, digital-access credential, or entry instruction, you authorize INTAMPA INC and assigned service personnel to enter the property for the scheduled service.

INTAMPA INC may decline to accept unrestricted access credentials. Keys and access devices remain the customer’s property and will be handled using reasonable care.

Unsafe conditions

INTAMPA INC may refuse, pause, or discontinue work when personnel reasonably believe that a condition presents a safety, health, legal, or property risk. Examples include aggressive animals, threatening conduct, unsafe structures, active electrical hazards, severe infestation, exposed needles, weapons, hazardous substances, extreme heat, severe weather, or inaccessible work areas.

Denied or delayed access

If personnel cannot enter the property, cannot access the work area, or must wait because the customer did not provide required access, INTAMPA INC may reschedule the service and charge a disclosed trip, mobilization, waiting-time, or late-cancellation fee.

9. Scheduling, Arrival Windows, and Delays

Appointment dates, arrival windows, project durations, and completion dates are estimates unless a service document expressly states that a date is guaranteed.

Scheduling may be affected by weather, traffic, labor availability, material availability, building access, permit processing, prior project delays, equipment failure, unsafe conditions, hidden damage, customer-requested changes, or other events outside reasonable control.

INTAMPA INC will use commercially reasonable efforts to communicate material schedule changes. A reasonable scheduling delay does not constitute abandonment or breach of contract.

Recurring services may be assigned to different qualified personnel. INTAMPA INC does not guarantee that the same technician or cleaning team will perform every appointment.

10. Payments, Deposits, and Billing

Payment obligations

Prices and payment schedules appear in the applicable estimate, proposal, work order, booking confirmation, invoice, or service agreement. Payment may be required:

• At booking.
• Before materials are ordered.
• Through an initial deposit and progress payments.
• Immediately after service completion.
• On a recurring billing schedule.
• According to another written payment schedule accepted by the customer.

Deposits and advance payments

A deposit may be required to reserve labor, purchase materials, rent equipment, schedule subcontractors, or begin work. The service document will identify whether a deposit is refundable and any conditions affecting the refund.

Taxes and additional charges

The customer is responsible for applicable taxes and for approved charges related to permits, disposal, parking, tolls, delivery, equipment rental, specialty materials, building access, or third-party services unless the service document states that those charges are included.

Payment authorization

By providing a payment method, you represent that you are authorized to use it. You authorize INTAMPA INC and its payment processor to charge approved deposits, invoices, recurring service amounts, cancellation charges, and other amounts described in an accepted service document.

Past-due amounts

If an amount remains unpaid after its due date, INTAMPA INC may suspend services, cancel future appointments, withhold delivery of nonessential project materials, or pursue lawful collection remedies.

Late charges, interest, collection expenses, and reasonable attorney fees apply only when stated in an accepted service document or otherwise recoverable under applicable law.

Billing disputes and chargebacks

Contact INTAMPA INC promptly if you believe an invoice is incorrect. Initiating a payment dispute or chargeback does not eliminate a valid payment obligation. Knowingly submitting a false chargeback or payment dispute may constitute a material breach of these Terms.

11. Cancellations, Rescheduling, and Refunds

Customer cancellations

Unless a service document states a different policy, customers should provide at least 24 hours of notice to cancel or reschedule an appointment.

A cancellation fee will apply only when it was disclosed in an accepted estimate, booking confirmation, work order, or service agreement. A customer may also be responsible for authorized and nonrecoverable costs already incurred, including:

• Special-order or custom-tinted materials.
• Equipment rentals.
• Permit or application fees.
• Delivery or disposal charges.
• Committed subcontractor costs.
• Labor already performed.
• Mobilization costs for personnel already dispatched.

Same-day and emergency services

Same-day, emergency, or priority appointments may become noncancelable after personnel are dispatched or materials are purchased when this condition is disclosed during booking.

Cancellation by INTAMPA INC

INTAMPA INC may cancel or reschedule a service because of safety concerns, severe weather, unavailable personnel, equipment failure, access problems, suspected unlawful activity, nonpayment, material misrepresentation, or another reasonable operational concern.

If INTAMPA INC cancels a service before work begins and cannot provide a reasonable alternative date, the customer will receive a refund of unused prepaid amounts. This refund does not include costs already incurred with customer authorization.

Refunds after services begin

Payments for completed labor, consumed materials, completed disposal, and other delivered services are not refundable except as stated in a written warranty, agreed corrective-work plan, or applicable law.

When a service concern can reasonably be corrected, INTAMPA INC may inspect the work and offer re-performance, repair, adjustment, or another appropriate remedy before issuing a refund.

12. Florida Consumer Rights

Nothing in these Terms waives a nonwaivable right or remedy available under Florida or federal consumer-protection law.

Home solicitation sales

When a transaction qualifies as a home solicitation sale under Florida law, the customer may have a statutory right to cancel until midnight of the third business day after signing the applicable agreement. INTAMPA INC will provide any separate written cancellation notice required for a qualifying transaction.

Any statutory notice provided for a qualifying home solicitation sale controls over a conflicting cancellation provision in these Terms. Information about Florida home solicitation cancellation rights appears in Section 501.025, Florida Statutes.

Construction lien rights

Certain improvements to real property may be subject to Florida’s Construction Lien Law. When applicable, INTAMPA INC, a contractor, subcontractor, supplier, or another lienor may provide notices and exercise rights permitted by Chapter 713, Florida Statutes.

Customers should review all notices carefully, confirm how project funds are applied, and request appropriate lien releases when making payments on projects covered by the law.

Unfair or deceptive practices

These Terms do not limit rights that cannot lawfully be waived under the Florida Deceptive and Unfair Trade Practices Act or another applicable consumer-protection law.

13. Service-Specific Conditions

Commercial and residential cleaning

Cleaning results depend on surface condition, age, material, previous treatment, maintenance history, water quality, ventilation, staining, odor sources, and available access. INTAMPA INC does not guarantee complete removal of every stain, odor, discoloration, mineral deposit, adhesive, paint mark, scratch, infestation, or contaminant.

The customer must identify surfaces requiring manufacturer-specific products or restrictions. INTAMPA INC may test a product in an inconspicuous area but cannot guarantee that every surface will react uniformly.

Standard cleaning does not include biohazard remediation, crime-scene cleaning, sewage remediation, pest treatment, mold remediation, hazardous waste handling, or extreme hoarding conditions unless separately evaluated and accepted in writing.

Junk removal and property cleanouts

The customer represents that they own the items designated for removal or have legal authority to dispose of them. Once removed, items may be discarded, recycled, donated, transferred, or processed at INTAMPA INC’s discretion unless a written agreement states otherwise.

The customer must clearly separate items that should remain. INTAMPA INC is not responsible for the removal of an item that a reasonable service provider would understand was designated for disposal.

INTAMPA INC may refuse hazardous, illegal, restricted, excessively heavy, infested, contaminated, or undisclosed materials. Prohibited or restricted items may include:

• Explosives, ammunition, or unsecured firearms.
• Medical waste, needles, bodily fluids, or biohazards.
• Asbestos-containing materials or lead-contaminated debris.
• Fuel, propane, pesticides, industrial chemicals, or unknown liquids.
• Radioactive materials or regulated electronic waste.
• Items that cannot lawfully be transported or disposed of through available facilities.

Additional disposal or handling fees may apply when the actual volume, weight, material type, access condition, or disposal classification differs from the information provided.

Interior painting

The customer is responsible for final color and finish approval. Digital screens, photographs, printed samples, existing paint, lighting, wall texture, application method, and product formulation may cause visible color differences.

Exact matching of aged, faded, weathered, repaired, discontinued, or previously mixed paint is not guaranteed. Touch-ups may remain visible because of changes in sheen, texture, lighting, porosity, or paint age.

Unless included in the scope, painting does not correct active leaks, excessive moisture, structural movement, recurring cracks, failing substrates, mold growth, or concealed damage.

Lead-based paint

Work that disturbs painted surfaces in certain pre-1978 homes or child-occupied facilities may be subject to the federal Lead Renovation, Repair and Painting Rule. Covered work will not proceed unless applicable disclosure, certification, containment, work-practice, and recordkeeping requirements can be satisfied.

Drywall repairs

Drywall repair may reveal concealed plumbing, electrical wiring, framing defects, water damage, mold, pests, insulation problems, or structural movement. Repair of these conditions is not included unless stated in an approved change order.

Patched areas may remain visible under certain lighting or viewing angles. Texture and paint matching are approximate unless the service document provides a specific finishing standard.

Handyman services liability boundaries

Handyman services are limited to the tasks described in the accepted scope. INTAMPA INC does not assume responsibility for an entire system, structure, appliance, fixture, or installation merely because personnel repair, adjust, assemble, maintain, or replace one component.

A requested repair may be declined when it exceeds the lawful or practical scope of handyman work or requires a specialized license, permit, manufacturer authorization, engineering review, or code-compliance evaluation.

Airbnb and rental properties

The customer is responsible for providing accurate turnover schedules, guest departure times, check-in times, access information, property rules, linen requirements, supply standards, and damage-reporting procedures.

INTAMPA INC is not responsible for guest conduct, booking-platform penalties, lost rental income, delayed guest departures, missing owner supplies, undisclosed damage, or an owner’s decision to permit occupancy before work is complete.

14. Materials, Products, and Equipment

Company-supplied materials

INTAMPA INC may select commercially reasonable products and materials suitable for the requested service unless the customer approves a specific brand, model, color, finish, or specification.

Product availability, manufacturer changes, discontinued items, supply interruptions, and lot variations may require substitution. Material substitutions require customer approval when they materially change appearance, performance, or price.

Customer-supplied materials

When the customer supplies products, fixtures, hardware, paint, replacement parts, appliances, or other materials, the customer is responsible for confirming that they are complete, compatible, lawful, suitable, undamaged, and available when needed.

INTAMPA INC is not responsible for defects, failures, delays, incompatibility, missing components, inaccurate instructions, insufficient quantities, or warranty restrictions associated with customer-supplied materials.

Manufacturer warranties

Manufacturer warranties belong to the customer to the extent transferable. INTAMPA INC does not expand, replace, or guarantee a manufacturer’s warranty.

15. Pre-Existing Conditions and Property Damage

Pre-existing and latent conditions

INTAMPA INC is not responsible for pre-existing damage, normal wear, concealed defects, latent defects, code violations, improper installation, defective products, structural movement, water intrusion, rot, corrosion, weak fasteners, brittle materials, loose finishes, failed coatings, pest damage, mold, or deterioration unrelated to INTAMPA INC’s work.

Routine cleaning, pressure, vibration, moisture, surface preparation, removal, disassembly, or repair may expose an existing weakness. Examples include peeling paint, loose grout, deteriorated caulk, weakened drywall, corroded hardware, unstable shelving, aged seals, cracked glass, loose veneer, and delaminated surfaces.

Documentation

INTAMPA INC may photograph or record the work area before, during, and after service to document property condition, progress, completion, safety concerns, or damage. Project documentation will be handled according to the INTAMPA INC Privacy Policy.

Reporting damage

The customer must report suspected damage caused by INTAMPA INC as soon as reasonably practical after discovery. The customer must provide photographs, preserve relevant evidence, and allow INTAMPA INC a reasonable opportunity to inspect and evaluate the condition before repair by another provider, except when immediate action is reasonably necessary to prevent further damage or protect safety.

INTAMPA INC may repair verified damage, arrange repair through a qualified provider, reimburse a reasonable repair cost, or submit the matter to an applicable insurer.

16. Workmanship, Warranties, and Disclaimers

Workmanship

INTAMPA INC will perform accepted services using commercially reasonable care and in a workmanlike manner consistent with the written service scope.

Express warranties

A workmanship warranty applies only when it is stated in an accepted service document. The written warranty will control its duration, coverage, exclusions, notice requirements, and remedies.

Warranty exclusions

Unless a written warranty states otherwise, coverage does not extend to:

• Pre-existing, concealed, or customer-created conditions.
• Ordinary wear, misuse, neglect, abuse, impact, or unauthorized alteration.
• Water intrusion, moisture, mold, pests, structural movement, or foundation movement.
• Failure of customer-supplied or manufacturer-supplied products.
• Damage caused by another contractor, occupant, guest, tenant, animal, weather event, or utility failure.
• Color, texture, sheen, or finish variations within commercially reasonable tolerances.
• Recurring stains, odors, cracks, peeling, corrosion, or damage caused by an unresolved source.
• Conditions outside the accepted scope of work.

INTAMPA INC does not guarantee that every cleaning result will be permanent, every stain or odor will be removed, every repair will correct an undisclosed underlying condition, or every website function will operate without interruption.

17. Limitation of Liability

Excluded damages may include lost profits, lost revenue, lost rent, lost bookings, business interruption, loss of use, loss of data, reputational harm, emotional distress, replacement accommodation, substitute-service expenses, or other economic loss that is not the direct and foreseeable result of INTAMPA INC’s breach.

To the maximum extent permitted by law, INTAMPA INC’s aggregate liability arising from a specific service will not exceed the amount the customer paid INTAMPA INC for the portion of the service directly giving rise to the claim.

The limitations in this section apply regardless of whether a claim is based on contract, warranty, negligence, tort, statute, strict liability, or another legal theory, and regardless of whether the possibility of damages was disclosed.

These limitations do not exclude liability for fraud, intentional misconduct, gross negligence, or another liability that cannot lawfully be waived, excluded, or limited. They also do not restrict a nonwaivable consumer remedy.

18. Customer Indemnification

To the extent permitted by law, the customer agrees to defend, indemnify, and hold harmless INTAMPA INC and its officers, directors, employees, agents, and service providers from third-party claims, losses, liabilities, damages, judgments, and reasonable expenses arising from:

• The customer’s material breach of these Terms or a service agreement.
• The customer’s negligence or intentional misconduct.
• False, incomplete, or misleading information supplied by the customer.
• The customer’s lack of authority to order work, grant access, or dispose of property.
• An undisclosed dangerous, illegal, hazardous, or contaminated property condition.
• The customer’s violation of a law, lease, association rule, contract, or third-party right.
• Customer-supplied materials, instructions, designs, content, or specifications.

This indemnification does not apply to the extent a claim results from INTAMPA INC’s own negligence, gross negligence, fraud, or intentional misconduct.

19. Website Use and Prohibited Conduct

INTAMPA INC grants you a limited, revocable, nonexclusive, nontransferable right to access the website for lawful personal or business purposes related to evaluating or purchasing our services.

You may not:

• Use the website for fraud, harassment, impersonation, or unlawful activity.
• Submit false information or requests on behalf of another person without authority.
• Attempt to gain unauthorized access to the website, server, accounts, forms, or connected systems.
• Introduce malware, harmful code, automated attacks, or disruptive technology.
• Scrape, copy, extract, reproduce, or republish website content through automated means without written permission.
• Interfere with website security, availability, performance, or operation.
• Use INTAMPA INC content, branding, or forms to misrepresent an affiliation or endorsement.
• Submit unlawful, threatening, defamatory, infringing, obscene, or malicious content.

INTAMPA INC may restrict website access, block submissions, preserve evidence, or report suspected unlawful activity to appropriate authorities.

20. Intellectual Property

The website and its original content, including text, service descriptions, designs, layouts, graphics, photographs, videos, logos, icons, branding, code, and downloadable materials, are owned by INTAMPA INC or used with permission.

These materials are protected by applicable copyright, trademark, trade-dress, and other intellectual-property laws.

You may view and print a reasonable number of pages for personal evaluation of INTAMPA INC services. You may not copy, modify, distribute, sell, license, publish, frame, reproduce, create derivative works from, or commercially exploit website content without prior written authorization.

“INTAMPA INC,” associated logos, service names, and brand elements may not be used in a way that suggests sponsorship, affiliation, or endorsement without written permission.

Customer-submitted content

You retain ownership of photographs, plans, descriptions, reviews, and other content you submit. You grant INTAMPA INC a limited license to use that content as reasonably necessary to prepare estimates, perform services, communicate with you, document work, resolve disputes, and maintain business records.

INTAMPA INC will not use identifiable project photographs for public advertising without permission when consent is required by law or agreement.

21. Privacy, Electronic Communications, and Signatures

Privacy

Personal information is handled according to the INTAMPA INC Privacy Policy, which is incorporated into these Terms by reference.

Electronic communications

You consent to receive service-related communications through email, telephone, text message, website forms, electronic invoicing systems, or other contact methods you provide.

Service-related communications may include estimates, booking confirmations, access questions, arrival notices, project updates, change orders, invoices, payment reminders, and responses to customer-support requests.

Electronic signatures and records

You agree that electronic approvals, checked boxes, typed signatures, email confirmations, text-message approvals, online payments, and similar electronic actions may serve as your signature and evidence of agreement when legally permitted.

Electronic records and signatures may have legal effect under Section 668.50, Florida Statutes.

22. Refusal, Suspension, and Termination of Services

INTAMPA INC may refuse, suspend, or terminate a service relationship when:

• The customer fails to make a required payment.
• The customer provides materially false or misleading information.
• The property presents an undisclosed or unacceptable safety risk.
• The customer, occupant, guest, or representative threatens, harasses, discriminates against, or abuses personnel.
• The requested work is unlawful, unethical, outside the agreed scope, or beyond applicable licensing limits.
• The customer repeatedly denies access or prevents reasonable performance.
• Continuing the service would expose people, property, or the environment to unreasonable risk.
• The customer materially breaches these Terms or another service agreement.

Termination does not eliminate the customer’s obligation to pay for completed work, authorized materials, nonrecoverable costs, or other amounts earned before termination.

Provisions concerning payment, intellectual property, warranties, liability, indemnification, disputes, and general contract interpretation survive termination when their nature requires survival.

23. Events Beyond Reasonable Control

INTAMPA INC is not liable for delay, interruption, or inability to perform caused by events beyond its reasonable control. These events may include:

• Hurricanes, tropical storms, flooding, lightning, fire, or other severe weather.
• Government orders, emergencies, evacuation orders, or road closures.
• Utility, internet, telephone, transportation, or payment-system failures.
• Labor shortages, illness, epidemics, pandemics, or supply-chain interruptions.
• Material shortages, manufacturer delays, or equipment failure.
• Acts of war, terrorism, civil unrest, vandalism, or criminal activity.
• Unexpected permit, inspection, building-access, or association delays.

Performance deadlines will be extended for a commercially reasonable period. If the delay makes performance impractical, either party may cancel the unperformed portion of the service, subject to payment for completed work and authorized nonrecoverable costs.

24. Dispute Resolution, Florida Law, and Jurisdiction

Informal dispute notice

Before filing a lawsuit, the complaining party must provide written notice describing the dispute, relevant service, requested resolution, and supporting information. The notice must be delivered to:

INTAMPA INC
4830 West Kennedy Boulevard Suite 600
Tampa, FL 33609
Email: hello@servicesintampa.com

The parties will make a good-faith effort to resolve the dispute for at least 30 days after receipt of the notice. This requirement does not prevent either party from seeking urgent injunctive relief, preserving a lien or statutory deadline, reporting a safety issue, or filing a claim when delay would cause a legal right to expire.

Governing law

These Terms, the website, and all service agreements are governed by the laws of the State of Florida, without regard to conflict-of-law principles.

Exclusive jurisdiction and venue

Except where applicable law requires a different forum, any legal action arising from these Terms, the website, or INTAMPA INC services must be filed exclusively in:

• A state court of competent jurisdiction located in Hillsborough County, Florida.
• The United States District Court for the Middle District of Florida, Tampa Division, when federal jurisdiction exists.

Each party consents to the personal jurisdiction of those courts and waives objections based on venue or an inconvenient forum.

Jury-trial waiver

Nothing in this section prevents an eligible claim from being filed in a small-claims court located in Hillsborough County, Florida.

25. General Contract Terms

Entire agreement

These Terms and the applicable service documents constitute the entire agreement concerning the subject matter they cover. They replace prior oral or written discussions concerning that same subject matter.

Severability

If a court determines that a provision is unlawful or unenforceable, the provision will be enforced to the maximum lawful extent or modified as narrowly as necessary. The remaining provisions will continue in effect.

No waiver

A failure or delay in enforcing a provision does not waive the right to enforce it later. A waiver is effective only when stated in writing by the party granting it.

Assignment

The customer may not assign a service agreement or transfer rights or obligations without prior written consent from INTAMPA INC. INTAMPA INC may assign an agreement as part of a merger, acquisition, restructuring, sale of assets, financing, or transfer of business operations.

Independent parties

Nothing in these Terms creates a partnership, joint venture, franchise, employment relationship, fiduciary relationship, or agency relationship between the customer and INTAMPA INC.

No third-party beneficiaries

These Terms benefit only the parties to the applicable agreement and their permitted successors and assigns. They do not create enforceable rights for another person unless a service document expressly states otherwise.

Headings

Headings and the Table of Contents support readability. They do not limit or alter the meaning of a provision.

Interpretation

Words such as “including” and “include” mean “including without limitation.” Singular terms include the plural when the context requires. A reference to a law includes valid amendments and successor provisions.

26. Modifications to These Terms

INTAMPA INC may update these Terms to reflect changes in services, technology, business practices, legal requirements, or risk-management procedures.

Updated Terms will be posted on this page with a revised effective date. Changes apply to website use and new transactions after the updated Terms become effective.

A material change will not retroactively alter the price, scope, or essential obligations of an already accepted service agreement unless both parties agree or applicable law requires the change.

Continuing to use the website after updated Terms become effective constitutes acceptance of the updated website-use provisions.

27. Contact INTAMPA INC

Contact INTAMPA INC with questions about these Terms and Conditions, a service agreement, an invoice, or a dispute.